Du finder os her
Agreement Between Building Contractor And Owner
While the owners own land with #________ ___ (address of the land on which the construction is carried out) and wish to build a house on said land, in accordance with the chartered architect`s plan and the specifications, steps and quantities that are attached to this contract and are part of this agreement. A contractor should provide services within the set deadlines. The owner who receives goods and services should ensure that the provision of the service complies with the requirements. You can include different milestones and delivery points. If the delivery does not match the milestone, you will be notified. The Owner may engage and pay other persons to remedy such defects and defects, and the costs and costs arising therefrom shall be borne/corrected and/or recovered by the Contractor, on any money, including the retention indemnity, which may be due to the Civil Contractor or other costs. Use our construction contract to indicate the work to be performed by a contractor for a real estate owner. 12. The contract shall be executed in duplicate, the original shall be kept by the owner and the duplicate by the contracting authorities. Before handing over the building to the owner, the maintenance period should be indicated in the contract. In most cases, the duration of maintenance is from six months to one year. If the contractor`s request is appropriate, the request is processed by the owner. If the owner is not satisfied with the extension beyond a reasonable period, the contractor is liable for damages.
11. Any dispute or dispute concerning the specifications, drawings, drawings and quality of the treatment or material used at work, or any other matter arising out of or in connection with the contract, project, drawings, specifications, orders or any other element related to the contract or the performance of the work; either during the progress of the work or after its completion or task, two arbitrators, one of whom shall be appointed by each of the parties, shall be referred to the single arbitration. Arbitrators appoint an arbitrator before entering the letter of reference. The parties would work with arbitrators and evidence, etc. if one of the parties does not cooperate or remains absent from the reference, the arbitrator or arbitrator is free to continue with the ex parte reference. The arbitrator or arbitrator shall keep a record of the oral evidence presented by the parties and present it to the court at the time of filing the award, together with the exhibits presented by the parties or their witnesses. The arbitrator`s or arbitrator`s proceedings shall be recorded in English and each party shall have a copy thereof. Arbitrators or arbitrators shall have the right to appoint a stenographer for the registration of the arbitration and to consult an expert, the costs being borne equally by the parties, after prior notification by the parties.
The fees of the arbitrator appointed by a party shall be borne by the party, so that the appointment and fees of the arbitrator and other arbitration costs shall be borne equally by the parties. The arbitrators shall render their arbitral award with reasons within six months from the date of seizure of the reference. Where the arbitrators allow their time to proceed without an arbitral judgment or have served a party or the arbitrator with written notice that they do not agree, the arbitrator shall immediately respond to the reference. The arbitrator shall make his distinction within months of travel following the entry of the reference or within as long as the parties may agree. . . .